Welcome to londonhomesandrealestateforsale.com. These Terms and Conditions govern the use of our services for home extensions in North London. By engaging with us, you agree to these terms, which form a legally binding contract between you (the client) and us (the company). We aim to deliver exceptional home extension projects while ensuring clarity and fairness in our dealings. You can learn about us.
Services Provided
We specialise in designing, planning, and constructing home extensions tailored to your needs in North London. Our services include:
- Initial consultation and project scoping.
- Architectural design and planning permission assistance.
- Construction and project management.
- Final inspection and handover.
All project specifics, including timelines and costs, will be outlined in a separate written agreement.
Client Responsibilities
To ensure a smooth project, you agree to:
- Provide accurate information about your property and requirements.
- Secure any necessary permissions or approvals not covered by our services.
- Make payments as agreed in the project contract.
- Grant reasonable access to your property for our team and contractors.
Payment Terms
Payments for our services will be detailed in your project contract. Typically:
- A deposit is required upon signing the contract.
- Progress payments are due at key milestones (e.g., design completion, construction stages).
- Final payment is due upon project completion and your approval.
Late payments may incur interest at 4% above the Bank of England base rate, and we reserve the right to suspend work until payment is received.
Cancellations and Termination
You may cancel a project before work begins by notifying us in writing, though the deposit may be non-refundable. We may terminate the contract if:
- You fail to meet payment obligations.
- You breach these terms materially.
In such cases, you’ll be liable for costs incurred up to termination.
Liability and Warranties
We warrant that our work will be carried out with reasonable skill and care, using quality materials. However:
- We are not liable for delays or issues caused by factors beyond our control (e.g., weather, supplier delays).
- Our liability for defects is limited to repair or replacement within 12 months of completion, excluding wear and tear.
- We are not responsible for indirect or consequential losses (e.g., loss of profit).
Intellectual Property
All designs, plans, and drawings created by us remain our intellectual property. You may use them solely for the agreed project and not reproduce them without our consent.
Governing Law
These Terms and Conditions are governed by the laws of England and Wales. Any disputes will be subject to the exclusive jurisdiction of the courts of England and Wales.
Changes to These Terms
We may update these Terms and Conditions from time to time. The current version, effective as of 20 February 2025, will always be available on our website.
Contact Us
For questions or concerns about these terms, please contact us.